HomeMy WebLinkAboutJohnson's Custom Landscaping 2023-03-22 COU 2223-165
SHORT FORM CONSTRUCTION CONTRACT
This Agreement is made and entered on March 22,2023 in Ukiah,California, by and between
Johnson's Custom Landscaping, a corporation ("Contractor") and the City of Ukiah ("City"),a general
law municipal corporation.
RECITALS:
1. The scope for this work ("the Work") is contained in Exhibit A, which is attached hereto
and incorporated herein by this reference.
2. Contractor is properly licensed and qualified to perform the work.
3. Whenever this Agreement calls for City approval or notification, the approval or
notification must be signed by the City Manager or his or her designee.
AGREEMENT:
Wherefore, in consideration of the foregoing facts and the terms and conditions as further
stated herein,the parties hereby agree as follows.
1. PERFORMANCE OF THE WORK
Contractor will perform the Work as further provided herein.
1.1 Time of Performance.Contractor shall commence the Work on or before March 1, 2023,
and will continue to perform the work on a monthly basis for 36 months.
1.1.1. NNLA[checkifapplicable]It is agreed by the parties to the contract that time is of
the essence and that, in case all the work is not completed before or upon the expiration of the
time limit as set forth, damage, other than those cost items identified in section 1.1.2, will be
sustained by the City and that it is and will be impracticable to determine the actual amount of
damage by reason of such delay; and it is therefore agreed that, subject to Sections 1.13-1.14,
below, the Contractor will pay to the City the sum of five hundred dollars ($500.00) per day for
each and every calendar day's delay beyond the time prescribed.
1.1.2 N/A[checkifapplicable]In case the work called for under this contract is not
completed within the time limit stipulated herein, the City shall have the right as provided
hereinabove, to extend the time of completion thereof. If the time limit be so extended, the
City shall have the right to charge to the Contractor and to deduct from the final payment for
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
1
COU 2223-165
the work the actual cost to the City of engineering, inspection, superintendence and other
overhead expenses which are directly chargeable to the contract and which accrue during the
period of such extension, except that the cost of final unavoidable delays shall not be included
in such charges.
1.2 Construction of Contract Documents. Contractor will perform the Work in compliance
with the plans and specifications set forth in the attached Exhibit A. If there is any inconsistency or
conflict between the plans and the specifications, the specifications will prevail. If there is any
inconsistency between the plans and the specifications and this agreement, the terms of this
Agreement shall prevail, unless expressly stated otherwise in a particular specification.
1.3 Contractor furnished items. Contractor will furnish all necessary labor, materials,tools,
equipment, and transportation necessary to perform the Work.
1.4 SB 854 requirements
1.4.1 No contractor or subcontractor may be listed on a bid proposal for a public
works project unless registered with the Department of Industrial Relations pursuant to Labor
Code section 1725.5 [with limited exceptions from this requirement for bid purposes only
under Labor Code section 1771.1(a)].
1.4.2 No contractor or subcontractor may be awarded a contract for public work on a
public works project unless registered with the Department of Industrial Relations pursuant to
Labor Code section 1725.5.
1.4.3 This project is subject to compliance monitoring and enforcement by the
Department of Industrial Relations.
1.4.4 The Labor Commissioner through the Division of Labor Standards Enforcement
(DLSE) may at any time require contractors and subcontractors to furnish electronic certified
payroll records directly to DLSE. All contractors and subcontractors must furnish electronic
certified payroll records directly to the DLSE.
1.4.5 The Prime Contractor is required to post job notices at the job site as prescribed
by regulations (currently, 8 CCR §16451(d).)
1.5 Use of Employees.
1.5.1. Contractor and any subcontractors shall pay all mechanics and laborers
employed by them to work upon the site of the work unconditionally and without subsequent
deductions or rebate on any account the full amounts due at the time of payment at wage rates
not less than those contained in the applicable prevailing wage determination, regardless of any
contractual relationship which may be alleged to exist between the Contractor and
subcontractors and such laborers and mechanics.
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
2
COU 2223-165
1.5.2. Contractor shall comply with the California Labor Code Section 1775. In
accordance with said Section 1775, Contractor shall forfeit as a penalty to the City, $50.00 for
each calendar day or portion thereof, for each workman paid less than the stipulated prevailing
rates for such work or craft in which such workman is employed for any work done under the
Contract by him or her or by any subcontractor under him or her in violation of the provisions of
the Labor Code and in particular, Labor Code Sections 1770 to 1780, inclusive. In addition to said
penalty and pursuant to Section 1775, the difference between such stipulated prevailing wage
rates and the amount paid to each workman for each calendar day or portion thereof for which
each workman was paid less than the stipulated prevailing wage rate shall be paid to each
workman by the Contractor.
1.5.3. Pursuant to the provision of Section 1770 of the Labor Code of the State of
California, City has ascertained the general prevailing rate of wages (which rate includes
employer payments for health and welfare, vacation, pension and similar purposes) applicable
to the work to be done, for straight time work. The holiday wage rate listed shall be applicable
to all holidays recognized in the collective bargaining agreement of the particular craft,
classification, or type of workers concerned. Copies of the General Prevailing Wage
Determination are on file in the office of the City Engineer and are available to the Contractor on
request. The Contractor shall post the wage determination at the site of work in a prominent
place where the workers can easily see it.
1.5.4. City will not recognize any claim for additional compensation because the
Contractor has paid any rate in excess of the prevailing wage rate obtained from the City Engineer.
The possibility of wage increases is one of the elements to be considered by the Contractor in
determining his or her bid and will not in any circumstances be considered as the basis for a claim
against the City.
1.5.5. Travel and Subsistence Payments.
Contractor shall make travel and subsistence payments to each worker needed to
execute the work in accordance with the requirements in Section 1773.8 of the Labor Code(Chapter
880, Statutes of 1968).
1.5.6. Apprentices.
Attention is directed to the provisions in Sections 1777.5 (Chapter 1411, Statutes
of 1968) and 1777.6 of the California Labor Code concerning the employment of apprentices by
the Contractor or any subcontractor under him. Contractor and any subcontractor under him or
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
3
COU 2223-165
her shall comply with the requirements of said sections in the employment of apprentices.
Information relative to apprenticeship standards, wage schedules and other
requirements may be obtained from the Director of Industrial Relations, ex officio the
Administrator of Apprenticeship, San Francisco, California, or from the Division of
Apprenticeship Standards and its branch offices.
Copies of Labor Code Sections 1771 (requiring prevailing wages), 1775 (imposing penalties,
including a$50 per day, per worker forfeiture,for failure to pay prevailing wages), 1776(requiring
contractor to maintain available for inspection certified payroll records), 1777.5 (requiring
certain apprenticeship programs), 1813 (imposing penalties for failure to make records available
for inspection) and 1815 (requiring time and Y2 for overtime) are available at the Department of
Industrial Relations website at http://www.dir.ca.gov/
1.6 CITY Inspector. CITY may designate an architect, engineer, other design professional or
other inspector ("Inspector") to supervise and/or inspect Contractor's performance of the Work.
The Inspector shall have no authority to change the Work, the compensation for performing the
Work or the time for completing the Work without City's prior written approval. City shall notify the
Contractor in writing, if it designates an Inspector.
1.7 Site Conditions. Contractor acknowledges that it has inspected the work site and any
improvements involving the Work and satisfied itself as to the conditions which can affect the Work
or its cost. Contractor has not relied on any representation by CITY or its officers or employees as
to the condition of the site or the houses or any condition that might affect the cost of performing
this Agreement.
1.8 New Products Required. All equipment, materials or fixtures furnished by Contractor
under this Agreement shall be new and of the most suitable grade for the intended purpose, unless
otherwise specifically provided.
1.9 Compliance with Laws. The Contractor shall give all notices and comply with all
applicable laws, ordinances, codes, rules and regulations. The Contractor shall secure and pay for
all permits,fees, and licenses necessary for the proper execution and completion of the work.
1.10 Protection of Site and Improvements. The Contractor shall preserve and protect the
site, grounds and any involved improvements and shall not alter or damage any portion thereof,
except as is absolutely necessary in order to perform the Work. The Contractor shall repair or
replace, as directed by CITY, any property that it damages, looses or destroys in violation of this
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
4
COU 2223-165
paragraph. Contractor shall assume full responsibility for maintaining the safety of the worksite in
compliance with all applicable state and federal worker safety and protection laws and shall
maintain the worksite in compliance with all such laws.
1.11 Inspection of Work. The Contractor shall ensure that the Work is available for
inspection by CITY or its Inspector at all reasonable times and that no work is covered up or rendered
incapable of inspection without prior notice to CITY or its Inspector and a reasonable opportunity
for inspection. The presence or absence of an CITY inspector or the conduct of an inspection by CITY
or its Inspector shall not relieve the Contractor from any contract requirement or compliance with
Exhibit A.
1.12 Title. The Contractor warrants that it conveys full and complete title, free of all liens
and encumbrances, to all materials, supplies, fixtures and equipment furnished to CITY under this
Agreement and agrees to fully defend and indemnify CITY, its officers and employees, and the
houses and homebuyers included in the Work from and against any claim, lien, charge, debt, cost,
expense or liability arising from a breach of said warranty.
1.13 Warranties. In addition to any other warranties in this contract, the Contractor
warrants that the Work conforms to the contract requirements and is free of any defect in
equipment, material or workmanship for a period of one year from the date of final acceptance of
the Work by CITY. If CITY accepts any part of the Work before final acceptance of the entire Work,
the warranty shall continue for the period of one year from the date of such partial acceptance.The
Contractor shall remedy, at the Contractor's expense, any failure to conform, or any defect. [Initial
if following sentence applies /J /J] CITY shall retain _% of the Contract Amount to secure the
Contractor's warranty and shall remit the unused portion of that amount at the end of the warranty
period. The time limit of this warranty shall not apply to any latent defects, or gross negligence or
fraud on the part of the Contractor.
1.14. Extension of Time.
Should any delays occur which the City may consider unavoidable, as herein defined,the Contractor
shall, pursuant to his or her application, be allowed an extension of time proportional to said delay
or delays, beyond the time herein set forth, in which to complete this contract; and liquidated
damages for delay shall not be charged against the Contractor by the City during an extension of
time granted because of unavoidable delay or delays.
Any claim by Contractor for a time extension based on unavoidable delays shall be based on written
notice delivered to the City within 15 days of the occurrence of the event giving rise to the claim.
Failure to file said written notice within the time specified shall constitute a waiver of said claim.
Notice of the full extent of the claim and all supporting data must be delivered to the City within 45
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
5
COU 2223-165
days of the occurrence unless the City specifies in writing a longer period. All claims for a time
extension must be approved by the City and incorporated into a written change order.
1.15. Unfavorable Weather and Other Conditions.
During unfavorable weather and other conditions,the Contractor shall pursue only such portions of
the work as shall not be damaged thereby. No portions of the work whose satisfactory quality or
efficiency will be affected by any unfavorable conditions shall be constructed while these conditions
remain, unless, by special means or precautions approved by the City, the Contractor shall be able
to overcome them.
The Contractor shall be granted a time extension of one day for each unfavorable weather day that
prevents him or her from placing concrete forms or placing and finishing concrete or asphalt
concrete. Such unfavorable weather day is defined as a rain day where precipitation prevents the
contractor from performing the work more than four (4) continuous hours within the authorized
work period or a temperature day where the ambient temperature is below that specified for the
placement of materials associated with the controlling work item for more than four(4) continuous
work hours of the authorized work period.
1.16.Saturday,Sunday, Holiday and Night Work.
No work shall be done between the hours of 6 p.m. and 7 a.m., nor on Saturdays, Sundays or legal
holidays except such work as is necessary for the proper care and protection of work already
performed, or except in cases of absolute necessity and in any case only with the permission of the
City.
It is understood, however, that night work may be established as a regular procedure by the
Contractor if he or she first obtains the written permission of the City and that such permission may
be revoked at any time by the City if the Contractor fails to maintain at night adequate force and
equipment for reasonable prosecution and to justify inspection of the work.
1.17. Hours of Labor.
Eight (8) hours of labor shall constitute a legal day's work and the Contractor or any subcontractor
shall not require or permit more than eight hours of labor in a day from any person employed by
him or her in the performance of the work under this contract, unless paying compensation for all
hours worked in excess of eight (8) hours per day at not less than 1 % times the basic rate of pay.
The Contractor shall forfeit to the City, as a penalty,the sum of twenty-five dollars($25.00)for each
workman employed in the execution of the contract by him or her or by any subcontractor,for each
calendar day during which such laborer, workman, or mechanic is required or permitted to labor
more than eight hours in violation of the provisions of Section 1810 to 1816, inclusive, (Article 3,
Chapter 1, Part 7, Division 2) of the Labor Code of the State of California and any acts amendatory
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
6
COU 2223-165
thereof.
2. CONTRACT PRICE
CITY shall pay the Contractor for performance of this Agreement with a total not to exceed
amount of$36,540.
3. PAYMENT OF CONTRACT PRICE
3.1 City shall pay any invoice for completed work, and approved by the City, within thirty (30)
days of its receipt by City. All payments under this contract shall be made upon the presentation of
certificates in writing from the City and shall show that the work covered by the payments has been
done and the payments thereof are due in accordance with this contract.
4. INDEMNIFICATION AND INSURANCE.
4.1 Indemnification. The Contractor shall do all of the work and furnish all labor,
materials,tools and appliances,except as otherwise herein expressly stipulated, necessary or proper
for performing and completing the work herein required in the manner and within the time herein
specified. The mention of any specific duty or liability imposed upon the Contractor shall not be
construed as a limitation or restriction of any general liability or duty imposed upon the Contractor
by this contract, said reference to any specific duty or liability being made herein merely for the
purpose of explanation.
The right of general supervision by the City shall not make the Contractor an agent of the City and
the liability of the Contractorfor all damages to persons or to public or private property,arising from
the Contractor's execution of the work, shall not be lessened because of such general supervision.
Until the completion and final acceptance by the City of all the work under and implied by this
contract,the work shall be under the Contractor's responsible care and charge.The Contractor shall
rebuild, repair, restore and make good all injuries, damages, re-erections and repairs, occasioned or
rendered necessary by causes of any nature whatsoever,excepting only acts of God and none other,
to all or any portions of the work, except as otherwise stipulated.
To the fullest extent permitted by law, Contractor shall indemnify and hold harmless the City and its
officers,directors,agents,and employees from and against all claims,damages, losses and expenses
including but not limited to attorneys'fees, costs of suit, expert witness fees and expenses and fees
and costs of any necessary private investigators arising out of or resulting from the performance of
the work, provided that any such claim, damage, loss or expense (1) is attributable to bodily injury,
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
7
COU 2223-165
sickness, disease or death, or to injury to or destruction of tangible property, other than the work
itself, including the loss of use resulting therefrom and (2) is caused in whole or in part by any act or
omission of the Contractor, any subcontractor, or anyone directly or indirectly employed by any of
them, or anyone for whose acts any of them may be liable, regardless of whether or not it is caused
in part by a party indemnified hereunder, or by the negligence or omission of a party indemnified
herein.
In any and all claims against the City or any of its agents or employees by any employee of the
Contractor, any subcontractor, anyone directly or indirectly employed by any of them, or anyone
for whose acts any of them may be liable, the indemnification obligation shall not be limited in any
way by any limitation on the amount or type of damages, compensation or benefits payable by or
for the Contractor or any subcontractor under workers' or workmen's compensation acts, disability
benefit acts,or other employee benefit acts.The obligation to indemnify shall extend to and include
acts of the indemnified party which may be negligent or omissions which may cause negligence.
The City shall have the right to estimate the amount of such damage and to cause the City to pay
the same and the amount so paid for such damage shall be deducted from the money due the
Contractor under this contract; or the whole or so much of the money due or to become due the
Contractor under this contract as may be considered necessary by the City, shall be retained by the
City until such suits or claims for damages shall have been settled or otherwise disposed of and
satisfactory evidence to that effect furnished to the City.
4.2 Insurance. Contractor shall procure and maintain for the duration of the
contract insurance against claims for injuries to persons or damages to property which may
arise from or in connection with the performance of the work hereunder by the Contractor, his
agents, representatives, employees or subcontractors.
4.2.1. Minimum Scope of Insurance
Coverage shall be at least as broad as:
A. Insurance Services Office Commercial General Liability coverage (Form
No. CG 20 10 10 01 and Commercial General Liability—Completed
Operations Form No. CG 20 37 10 01).
B. Insurance Services Office form number CA 0001 (Ed. 1/87) covering
Automobile Liability, code 1 (any auto).
C. Worker's Compensation insurance as required by the State of California
and Employer's Liability Insurance.
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
8
COU 2223-165
4.2.2. Minimum Limits of Insurance
Contractor shall maintain limits no less than:
A. General Liability: $1,000,000 per occurrence for bodily injury, personal injury
and property damage including operations, products and completed
operations. If Commercial General Liability Insurance or other form with
a general aggregate limit is used, either the general aggregate limit shall apply
separately to this project/location or the general aggregate limit shall be twice
the required occurrence limit. Insurance must be written on an occurrence
basis.
B. Automobile Liability: $1,000,000 per accident for bodily injury and property
damage. Insurance must be written on an occurrence basis.
C. Worker's Compensation Employer's Liability: $1,000,000 per accident for
bodily injury or disease.
4.2.3. Deductibles and Self-insured Retentions
Any deductibles or self-insured retentions must be declared to and approved by the City. The
City may require the insurer to reduce or eliminate such deductibles or self-insured retentions
with respect to the City, its officers, officials, employees and volunteers; or the Contractor to
provide a financial guarantee satisfactory to the City guaranteeing payment of losses and
related investigations, claim administration and defense expenses; or to approve the deductible
without a guarantee.
4.2.4. REQUIRED Insurance Provisions
Proof of general liability and automobile liability policies are to contain, or be endorsed
to contain, the following provisions:
A. The City, its officers, officials, employees, and volunteers are to be covered as
ADDITIONAL INSURED with respect to liability arising out of automobiles owned, leased,
hired or borrowed by or on behalf of the contractor; and with respect to liability arising
out of work or operations performed by or on behalf of the Contractor including materials,
parts or equipment, furnished in connection with such work or operations. General
liability coverage can be provided in the form of an endorsement to the Contractor's
insurance, or as a separate owner's policy.
B. The workers' compensation policy is to be endorsed with a waiver of subrogation.
The insurance company, in its endorsement, agrees to waive all rights of subrogation
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
9
COU 2223-165
against the City, its officers, officials, employees and volunteers for losses paid under the
terms of this policy which arises from the work performed by the named insured for the
City. NOTE: You cannot be added as an additional insured on a workers' compensation
policy.
C. For any claims related to this project, the Contractor's insurance coverage shall be
primary insurance with respect to the City, its officers, officials, employees, and
volunteers. Any insurance or self-insurance maintained by the City, its officers, officials,
employees, or volunteers shall be in excess of the Contractor's insurance and shall not
contribute with it.
D. Each insurance policy required by this clause shall be endorsed to state that coverage
shall not be canceled by either party, except after thirty (30) days' prior written notice by
certified mail, return receipt requested, has been given to the City.
E. Note: (This protects the Contractor) -Coverage shall not extend to any indemnity
coverage for the active negligence of the additional insured in any case where an
agreement to indemnify the additional insured would be invalid under Subdivision (b) of
Section 2782 of Civil Code.
5. TERMINATION.
This Agreement may only be terminated by City: 1)for breach of the agreement; 2) because
funds are no longer available to pay Contractor for services provided under this Agreement; or 3)
City has abandoned and does not wish to complete the project for which Contractor was retained.
City shall notify Contractor of any alleged breach of the agreement and of the action required to
cure the breach. If Contractor fails to cure the breach within the time specified in the notice, the
contract shall be terminated as of that time. If terminated for lack of funds or abandonment of the
project, the contract shall terminate on the date notice of termination is given to Contractor. City
shall pay the Contractor only for services performed and expenses incurred as of the effective
termination date, unless terminated because the Contractor has failed to satisfactorily cure a breach
after notice in which event City shall:
a. retain any amounts earned under the Contract but not yet paid by City;
b. take possession of all material and fixtures on the job site;
c. have the right to complete the Work and recover from Contractor any increased cost to
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
10
COU 2223-165
complete the Work above the amounts that would have been paid to Contractor hereunder,
together with any other damages suffered by City as a result of said breach.
6. MODIFICATION OF AGREEMENT.
City may,from time to time, request changes in the Work,the time to complete the work or
the compensation to be paid for the Work. Such changes must be incorporated in written
amendments to this Agreement. To be effective, all such changes as referred to in this section must
be agreed upon in writing by both parties to this agreement.
7. ASSIGNMENT.
The Contractor shall not assign any interest in this Agreement, and shall not transfer any
interest in the same (whether by assignment or novation),without the prior written consent of City.
8. APPLICATION OF LAWS.
The parties hereby agree that all applicable Federal, State and local rules, regulations and
guidelines not written into this Agreement shall hereby prevail during the period of this Agreement.
9. INDEPENDENT CONTRACTOR.
It is the express intention of the parties hereto that Contractor is an independent contractor
and not an employee,joint venturer, or partner of City for any purpose whatsoever. City shall have
no right to, and shall not control the manner or prescribe the method of accomplishing those
services contracted to and performed by Contractor under this Agreement, and the general public
and all governmental agencies regulating such activity shall be so informed.
Those provisions of this Agreement that reserve ultimate authority in City have been
inserted solely to achieve compliance with federal and state laws, rules, regulations, and in-
terpretations thereof. No such provisions and no other provisions of this Agreement shall be
interpreted or construed as creating or establishing the relationship of employer and employee
between Contractor and City.
Contractor shall pay all estimated and actual federal and state income and self-employment
taxes that are due the state and federal government and shall furnish and pay worker's compensa-
tion insurance, unemployment insurance and any other benefits required by law for himself and his
employees, if any. Contractor agrees to indemnify and hold City and its officers, agents and
employees harmless from and against any claims or demands by federal, state or local government
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
11
COU 2223-165
agencies for any such taxes or benefits due but not paid by Contractor, including the legal costs
associated with defending against any audit, claim, demand or law suit.
Contractor warrants and represents that it is a properly licensed for the work performed
under this Agreement with a substantial investment in its business and that it maintains its own
offices and staff which it will use in performing under this Agreement.
10. GOVERNING LAW.
This Agreement shall be governed by and construed in accordance with the laws of the State
of California and any legal action concerning the agreement must be filed and litigated in the proper
court in Mendocino County, each party consenting to jurisdiction and venue of California state
courts in Mendocino County.
11. SEVERABILITY.
If any provision of the Agreement is held by a court of competent jurisdiction to be invalid,
void, or unenforceable, the remaining provisions shall nevertheless continue in full force and effect
without being impaired or invalidated in any way.
12. INTEGRATION.
This Agreement, including the exhibits attached hereto, contains the entire agreement
among the parties and supersedes all prior and contemporaneous oral and written agreements,
understandings, and representations among the parties. No amendments to this Agreement shall
be binding unless executed in writing by all of the parties.
13. WAIVER.
No waiver of any of the provisions of this Agreement shall be deemed, or shall constitute a
waiver of any other provision, nor shall any waiver constitute a continuing waiver. No waiver shall
be binding unless executed in writing by the party making the waiver.
14. NOTICES.
Whenever notice, payment or other communication is required or permitted under this
Agreement, it shall be deemed to have been given when personally delivered,emailed,or deposited
in the United States mail with proper first-class postage affixed thereto and addressed as follows:
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
12
COU 2223-165
CONTRACTOR CITY
Johnson's Custom Landscaping, Inc. City of Ukiah
Attn: Jim Johnson Attn: Cindy Sauers
591 Riverside Drive 300 Seminary Ave.
Ukiah, CA 9482 Ukiah, CA 95482
Email: jcl@mendomail.com Email: csauers@cityofukiah.com
Either party may change the address to which notices must be sent by providing notice of that
change as provided in this paragraph.
15. PARAGRAPH HEADINGS.
The paragraph headings contained herein are for convenience and reference only and are
not intended to define or limit the scope of this agreement.
16. EXECUTION OF AGREEMENT.
This Agreement may be executed in duplicate originals, each bearing the original
signature of the parties. Alternatively, this Agreement may be executed and delivered by
facsimile or other electronic transmission,and in more than one counterpart,each of which shall
be deemed an original, and all of which together shall constitute one and the same instrument.
When executed using either alternative, the executed agreement shall be deemed an original
admissible as evidence in any administrative or judicial proceeding to prove the terms and
content of this Agreement.
WHEREFORE,the parties have entered this Agreement on the date first written above.
CONTRACTOR CITY OF UKIAH C
By: L Lk2l, By:
IJI k cJ limns v.^i Sage Sangiacomo
J6,IhnSJA `S lv5fv,n, L��.��%i ; City Manager
California Contractor's License Number: 748725 'C
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
13
COU 2223-165
Exhibit A—Scope of Work
A. Landscape Maintenance at the City of Ukiah Electric Substation located at 1350 Hastings
Road, Ukiah, which will include all labor, materials and equipment at a rate of$665.00 per
month. The work includes the following:
• Spray, pull and trim all weeds in beds, cracks in walkway and driveway weekly as
needed.
Blow entries, walkways and driveway weekly.
Prune, hedge and trim all plantings as needed to keep nice.
Keep trees trimmed up to head height as needed.
Fertilize plantings and 2 times per year.
Shut down and winterize the irrigation system in the late fall when needed.
Start up the irrigation system in the spring and check for any problems.
B. Landscape Maintenance at the City of Ukiah Electric Utility Department Service Center
located at 724 South Orchard Avenue, Ukiah, which will include all labor, materials and
equipment at a rate of$350.00 per month. The work includes the following:
Blow walkway, entries and parking lot weekly (as needed).
Trim shrubs and perennials as needed to keep neat.
Fertilize plantings 2 times per year.
Weed and spray beds as needed.
Shut down and winterize the irrigation system in the late fall when needed.
Start up the irrigation system in the spring and check for any problems.
Contract 2223-165 - Johnson Custom Landscaping, Inc.
March 22, 2023
14