Loading...
HomeMy WebLinkAboutHDR Engineering, Inc. 2015-07-27COU No. 1516011 AGREEMENTFOR PROFESSIONAL CONSULTING SERVICES [Design Professional] This Agreement, made and entered into this 27th day of July, 2015 ("Effective Date"), by and between CITY OF UKIAH, CALIFORNIA, hereinafter referred to as "City" and HDR Engineering, Inc., a corporation organized and in good standing under the laws of the state of Nebraska, hereinafter referred to as "Consultant". RECITALS This Agreement is predicated on the following facts: a. City requires consulting services related to the Lake Mendocino Hydro -Electric Plant Site Visit and Inspection. b. Consultant represents that it has the qualifications, skills, experience and properly licensed to provide these services, and is willing to provide them according to the terms of this Agreement. C. City and Consultant agree upon the Scope -of -Work and Work Schedule attached hereto as Attachment "A", describing contract provisions for the project and setting forth the completion dates for the various services to be provided pursuant to this Agreement. TERMS OF AGREEMENT 1.0 DESCRIPTION OF PROJECT 1.1 The Project is described in detail in the attached Scope -of -Work (Attachment "A"). 2.0 SCOPE OF SERVICES 2.1 As set forth in Attachment "A". 2.2. Additional Services. Additional services, if any, shall only proceed upon written agreement between City and Consultant. The written Agreement shall be in the form of an Amendment to this Agreement. 3.0 CONDUCT OF WORK 3.1 Time of Completion. Consultant shall commence performance of services as required by the Scope -of -Work upon receipt of a Notice to Proceed from City and shall complete such services within 30 calendar days from receipt of the Notice to Proceed. Consultant shall complete the work to the City's reasonable satisfaction; even if contract disputes arise or Consultant contends it is entitled to further compensation. 4.0 COMPENSATION FOR SERVICES 4.1 Basis for Compensation. For the performance of the professional services of this Agreement, Consultant shall be compensated on a time and expense basis not to exceed a guaranteed maximum dollar amount of $4,000. Labor charges shall be based upon hourly billing rates for the various classifications of personnel employed by Consultant to perform the Scope of Work as set forth in the attached Attachment B, which shall include all indirect costs and expenses of every kind or nature, except direct expenses. The direct expenses and the fees to be charged for same shall be as set forth in Attachment B. Consultant shall complete the Scope of Work for the not -to -exceed guaranteed maximum, even if actual time and expenses exceed that amount. 4.2 Changes. Should changes in compensation be required because of changes to the Scope -of - Work of this Agreement, the parties shall agree in writing to any changes in compensation. "Changes to the Scope -of -Work" means different activities than those described in Attachment "A" and not additional time to complete those activities than the parties anticipated on the date they entered this Agreement. 4.3 Sub -contractor Payment. The use of sub -consultants or other services to perform a portion of the work of this Agreement shall be approved by City prior to commencement of work. The cost of sub -consultants shall be included within guaranteed not -to -exceed amount set forth in Section 4.1. 4.4 Terms of Payment. Payment to Consultant for services rendered in accordance with this contract shall be based upon submission of monthly invoices for the work satisfactorily performed prior to the date of invoice less any amount already paid to Consultant, which amounts shall be due and payable thirty (30) days after receipt by City. The invoices shall provide a description of each item of work performed, the time expended to perform each task, the fees charged for that task, and the direct expenses incurred and billed for. Invoices shall be accompanied by documentation sufficient to enable City to determine progress made and the expenses claimed. 5.0 ASSURANCES OF CONSULTANT 5.1 Independent Contractor. Consultant is an independent contractor and is solely responsible for its acts or omissions. Consultant (including its agents, servants, and employees) is not City's agent, employee, or representative for any purpose. It is the express intention of the parties hereto that Consultant is an independent contractor and not an employee, joint venturer, or partner of City for any purpose whatsoever. City shall have no right to, and shall not control the manner or prescribe the method of accomplishing those services contracted to and performed by Consultant under this Agreement, and the general public and all governmental agencies regulating such activity shall be so informed. Those provisions of this Agreement that reserve ultimate authority in City have been inserted solely to achieve compliance with federal and state laws, rules, regulations, and interpretations thereof. No such provisions and no other provisions of this Agreement shall be interpreted or construed as creating or establishing the relationship of employer and employee between Consultant and City. Consultant shall pay all estimated and actual federal and state income and self-employment taxes that are due the state and federal government and shall furnish and pay worker's compensation insurance, unemployment insurance and any other benefits required by law for himself and his employees, if any. Consultant agrees to indemnify and hold City and its officers, agents and employees harmless from and against any claims or demands by federal, state or local government agencies for any such taxes or benefits due but not paid by Consultant, including the legal costs associated with defending against any audit, claim, demand or law suit. Design — ProfSvcsAgreement-November 20, 2008 PAGE 2 OF 7 Consultant warrants and represents that it is a properly licensed professional or professional organization with a substantial investment in its business and that it maintains its own offices and staff which it will use in performing under this Agreement. 5.2 Conflict of Interest. Consultant understands that its professional responsibility is solely to City. Consultant has no interest and will not acquire any direct or indirect interest that would conflict with its performance of the Agreement. Consultant shall not in the performance of this Agreement employ a person having such an interest. If the City Manager determines that the Consultant has a disclosure obligation under the City's local conflict of interest code, the Consultant shall file the required disclosure form with the City Clerk within 10 days of being notified of the City Manager's determination. 6.0 INDEMNIFICATION 6.1 Insurance Liability. Without limiting Consultant's obligations arising under Paragraph 6.2 Consultant shall not begin work under this Agreement until it procures and maintains for the full period of time allowed by law, surviving the termination of this Agreement insurance against claims for injuries to persons or damages to property, which may arise from or in connection with its performance under this Agreement. A. Minimum Scope of Insurance Coverage shall be at least as broad as: 1. Insurance Services Office ("ISO) Commercial General Liability Coverage Form No. CG 20 10 10 01 and Commercial General Liability Coverage — Completed Operations Form No. CG 20 37 10 01. 2. ISO Form No. CA 0001 (Ed. 1/87) covering Automobile Liability, Code 1 "any auto" or Code 8, 9 if no owned autos and endorsement CA 0025. 3. Worker's Compensation Insurance as required by the Labor Code of the State of California and Employers Liability Insurance. 4. Errors and Omissions liability insurance appropriate to the consultant's profession. ' B. Minimum Limits of Insurance Consultant shall maintain limits no less than: General Liability: $1,000,000 combined single limit per occurrence for bodily injury, personal injury and property damage including operations, products and completed operations. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the general aggregate limit shall apply separately to the work performed under this Agreement, or the aggregate limit shall be twice the prescribed per occurrence limit. 2. Automobile Liability: $1,000,000 combined single limit per accident for bodily injury and property damage. Design — PmfSwsAgreement-November 20, 2008 PAGE 3 OF 7 3. Worker's Compensation and Employers Liability: Worker's compensation limits as required by the Labor Code of the State of California and Employers Liability limits of $1,000,000 per accident. 4. Errors and Omissions liability: $1,000,000 per essUrFenee claim. C. Deductibles and Self -Insured Retentions Any deductibles or self-insured retentions must be declared to and approved by the City. At the option of the City, either the insurer shall reduce or eliminate such deductibles or self-insured retentions as respects to the City, its officers, officials, employees and volunteers; or the Consultant shall procure a bond guaranteeing payment of losses and related investigations, claim administration and defense expenses. D. Other Insurance Provisions The policies are to contain, or be endorsed to contain, the following provisions: General Liability and Automobile Liability Coverages a. The City, it officers, officials, employees and volunteers are to be covered as additional insureds as respects; liability arising out of activities performed by or on behalf of the Consultant, products and completed operations of the Consultant, premises owned, occupied or used by the Consultant, or automobiles owned, hired or borrowed by the Consultant for the full period of time allowed by law, surviving the termination of this Agreement. The coverage shall contain no special limitations on the scope -of -protection afforded to the City, its officers, officials, employees or volunteers. b. The Consultant's insurance coverage shall be primary insurance as respects to the City, its officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees or volunteers shall be in excess of the Consultant's insurance and shall not contribute with it. C. Any failure of Consultant to comply with reporting provisions of the policies shall not affect coverage provided to the City, its officers, officials, employees or volunteers. d. The Consultant's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 2. Worker's Compensation and Employers Liability Coverage The insurer shall agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from Consultant's performance of the work, pursuant to this Agreement. Design — ProNvesAgreement-November 20, 2008 PAGE 4 OF 7 3. Professional Liability Coverage If written on a claims -made basis, the retroactivity date shall be the effective date of this Agreement. The policy period. shall extend one year of completion of work. 4. All Coverages Each Insurance policy required by this clause shall be endorsed to state that coverage shall not be suspended, vee ed, canceled by either party, reduced in coverage or in limits except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. E. Acceptability of Insurers Insurance is to be placed with admitted California insurers with an A.M. Best's rating of no less than A- for financial strength, AA for long-term credit rating and AMB -1 for short-term credit rating. F. Verification of Coverage Consultant shall furnish the City with Certificates of Insurance and with original Endorsements effecting coverage required by this Agreement. The Certificates and Endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The Certificates and Endorsements are to be on forms provided or approved by the City. All Certificates and Endorsements are to be received and approved by the City before Consultant begins the work of this Agreement. The City reserves the right to require complete, certified copies of all required insurance policies, at any time. If Consultant fails to provide the coverages required herein, the City shall have the right, but not the obligation, to purchase any or all of them. In that event, after notice to Consultant that City has paid the premium, the cost of insurance may be deducted from the compensation otherwise due the contractor under the terms of this Contract. G. Subcontractors Consultant shall include all sub -contractors or sub -consultants as insured under its policies or shall furnish separate certificates and endorsements for each sub -contractor or sub -consultant. All coverage for sub -contractors or sub -consultants shall be subject to all insurance requirements set forth in this Paragraph 6.1. 6.2 Indemnification. Notwithstanding the foregoing insurance requirements, and in addition thereto, Consultant agrees, for the full period of time allowed by law, surviving the termination of this Agreement, to indemnify the City for any claim, cost or liability that arises out of, or pertains to, or relates to any negligent act or omission or the willful misconduct of Consultant and its agents in the performance of services under this contract, but this indemnity does not apply to liability for damages for death or bodily injury to persons, injury to property, or other loss, arising from the sole negligence, willful misconduct or defects in design by the City, or arising from the active negligence of the City. "Indemnify," as used herein includes the expenses of defending against a claim and the payment of any settlement or judgment arising out of the claim. Defense costs include all Design — ProYSvcsAgreement-November 20, 2008 PAGE 5 OF 7 costs associated with defending the claim, including, but not limited to, the fees of attorneys, investigators, consultants, experts and expert witnesses, and litigation expenses. References in this paragraph to City or Consultant, include their officers, employees, agents, and subcontractors. 7.0 CONTRACT PROVISIONS 7.1 Documents and Ownership of Work. All documents furnished to Consultant by City and all documents or reports and supportive data prepared by Consultant under this Agreement are owned and become the property of the City upon their creation and shall be given to City immediately upon demand and at the completion of Consultant's services at no additional cost to City. Deliverables are identified in the Scope -of -Work, Attachment "A". All documents produced by Consultant shall be furnished to City in digital format and hardcopy. Consultant shall produce the digital format, using software and media approved by City. Any reuse of Consultant's Documents by the City on other projects not contemplated under this Agreement shall be at the City's sole risk, without legal liability to Consultant. 7.2 Governing Law. Consultant shall comply with the laws and regulations of the United States, the State of California, and all local governments having jurisdiction over this Agreement. The interpretation and enforcement of this Agreement shall be governed by California law and any action arising under or in connection with this Agreement must be filed in a Court of competent jurisdiction in Mendocino County. 7.3 Entire Agreement. This Agreement plus its Attachment(s) and executed Amendments set forth the entire understanding between the parties. 7.4 Severability. If any term of this Agreement is held invalid by a court of competent jurisdiction, the remainder of this Agreement shall remain in effect. 7.5 Modification. No modification of this Agreement is valid unless made with the agreement of both parties in writing. 7.6 Assignment. Consultant's services are considered unique and personal. Consultant shall not assign, transfer, or sub -contract its interest or obligation under all or any portion of this Agreement without City's prior written consent. 7.7 Waiver. No waiver of a breach of any covenant, term, or condition of this Agreement shall be a waiver of any other or subsequent breach of the same or any other covenant, term or condition or a waiver of the covenant, term or condition itself. 7.8 Termination. This Agreement may only be terminated by either party: 1) for breach of the Agreement; 2) because funds are no longer available to pay Consultant for services provided under this Agreement; or 3) City has abandoned and does not wish to complete the project for which Consultant was retained. A party shall notify the other party of any alleged breach of the Agreement and of the action required to cure the breach. If the breaching party fails to cure the breach within the time specified in the notice, the contract shall be terminated as of that time. If terminated for lack of funds or abandonment of the project, the contract shall terminate on the date notice of termination is given to Consultant. City shall pay the Consultant only for services performed and expenses incurred as of the effective termination date. In such event, as a condition to payment, Consultant shall provide to City all finished or unfinished documents, data, studies, surveys, drawings, maps, models, photographs and reports prepared by the Consultant under this Agreement. Consultant shall be entitled to Design — ProfSvcsAgreement-November 20, 2008 PAGE 6 OF 7 receive just and equitable compensation for any work satisfactorily completed hereunder, subject to off -set for any direct or consequential damages City may incur as a result of Consultant's breach of contract. 7.9 Execution of Agreement. This Agreement may be executed in duplicate originals, each bearing the original signature of the parties. Alternatively, this Agreement may be executed and delivered by facsimile or other electronic transmission, and in more than one counterpart, each of which shall be deemed an original, and all of which together shall constitute one and the same Instrument. When executed using either alternative, the executed agreement shall be deemed an original admissible as evidence in any administrative or judicial proceeding to prove the terms and content of this Agreement. 8.0 NOTICES Any notice given under this Agreement shall be In writing and deemed given when personally delivered or deposited in the mail (certified or registered) addressed to the parties as follows: CITY OF UKIAH MDR ENGINEERING, INC. DEPT. OF ELECTRIC UTILITY RICK JONES, PE 300 SEMINARY AVENUE 2379 GATEWAY OAKS, SUITE 200 UKIAH, CALIFORNIA 95482-5400 SACRAMENTO, CA 95833 9.0 SIGNATURES IN WITNESS WHEREOF, the parties have executed this Agreement the Effective Date: HDR ENGINEERING, INC. PRINT NAME: �wLt4 c. 1.v-tM- 4 47-0U*3'75( IRS IDN Number CITY OF UKIAH BY: SA6E 3,WGIACOM0 CITYMANAGER ATTEST KRISTINE LAWLER CITY CLERK Oatpa - ?mtSvczAQrc wm-Novae6cr 20 2068 PAGE 7OF7 r'7 --"3t —2r,tS Date Date g/g/rs- Date 01 hdrinc.com July 22, 2015 Mr. James O'Brien City of Ukiah 300 Seminary Avenue Ukiah, CA 95482 ATTACHMENT "A" CONTRACT 1516011 Via Email: jobrien a cityofukiah.com Subject: Lake Mendocino PH - Proposal for Site Visit and Inspection Dear Mr. O'Brien: HDR is pleased to present this proposal to the City of Ukiah (Ukiah) for a site visit and inspection at two facilities associated with its existing Lake Mendocino Powerhouse. Project Understanding Ukiah has been experiencing leakage at its existing power tunnel tainter gate, and would like to have the gate inspected so that mitigation alternatives can be determined through a future study. Reduction or elimination of the leakage would enhance hydroelectric generation at the facility. In addition, the existing transformer at the plant is operating poorly and is in need of repair or replacement. Ukiah would like the transformer to be inspected in order to support a future engineering alternative analysis for the preferred path forward (i.e., repair vs. replace). Scope of Work and Deliverable HDR will conduct a one -day site visit to the Lake Mendocino Powerhouse to perform the in of both the tainter gate and the transformer. A team of two to three engineers, including one structural engineer and one electrical engineer, will perform the site visit. One to two of the engineers will walk the tunnel to inspect the tainter gate, and one to two of the engineers will inspect the transformer. For the tainter gate inspection, the engineers assigned will be Confined Space certified. Following the inspection, HDR will provide a draft scope of work for both the tainter gate and the transformer which summarizes the findings of the inspection and provides the proposed approach for performing the alternatives analysis. This draft scope will be provided within two weeks of the inspection. 2379 Gateway Oaks, Suite 200, Sacramento, CA 95833 T 916.679.8700 F 916.679.8701 Mr. James O'Brien ATTACHMENT "A" July 22, 2015 CONTRACT 1516011 Page 2 Assumptions • HDR will bring PPE appropriate for walking to tainter gate location within tunnel, and Flame Resistant clothing appropriate for transformer inspection. Ukiah shall inform HDR if any additional PPE is necessary beyond this assumption. • HDR will not provide any engineering assessment as part of this proposed scope; this would be provided as part of a potential future work scope. Schedule Upon receipt of a Purchase Order, HDR will schedule the site visit with Ukiah. The dates below are hypothetical for the purposes of establishing a relative schedule. Schedule Task Completion Date HDR receives Purchase Order Early August 2015 HDR performs Site Visit/Inspection Mid -Late August 2015 (at Ukiah's discretion) HDR provides Draft Analysis Scope Late August— Early September 2015 Any delay in Purchase Order receipt will result in a corresponding delay in the aforementioned schedule. Project Team The following HDR staff will comprise the core group assigned to this project: Sam Planck, PE...............................................................................Sr. Structural Engineer Keith DeLapp, PE.............................................................................Sr. Structural Engineer Jeff Montano, PE.............................................................................. Sr. Electrical Engineer Additional HDR staff will provide project support on an as -needed basis. Compensation HDR requests a budget of $4,000 for the site visit and inspection, inclusive of time, materials and expenses. This estimate is based on an assumption that the project will be billed under a single work authorization and invoice by HDR, which will reduce internal costs. All work will be performed on a time -and -materials basis, and HDR will not exceed the estimated budget without prior authorization from Ukiah. If additional tasks, unforeseen Mr. James O'Brien July 22, 2015 Page 3 ATTACHMENT "A" CONTRACT 1516011 conditions, delays or project circumstances beyond those anticipated here arise, additional budget may be needed. Such a request would be the subject of an addendum to this scope. Terms and Conditions This project will be performed by HDR's office in Sacramento, CA. All activities associated with this scope of work will be performed in accordance with the terms and conditions of the Consultant Service Agreement (CSA) between HDR and Ukiah, effective August _, 2015. Consistent with the terms of the agreement, the standard rate schedule referenced in the CSA has been updated with the rate schedule that was provided to HDR by email dated July 22, 2015. HDR appreciates the opportunity to provide support to Ukiah. Please do not hesitate to contact Rick Jones at (916) 679-8731 if you have any questions or comments regarding this proposal. Sincerely, Rick Jones, PE Managing Principal cc: Mary Horger, City of Ukiah (mhorger@cityofukiah.com) Hari Modi, Cooper Compliance (h mod iOcoopercompliance.com) HDR HYDROPOWER STANDARD HOURLY RATE SHEET FOR 2015 (in US Dollars) Accounting Asst Sr Accounting Business Manager Receptionist Clerk Admin Asst Word Processor Exec Sec Coordinator CADDTechnician Electrical 1 CADDTechnician Electrical 2 CADDTechnician Electrical 3 CADDTechnician Electrical 4 CADDTechnician General 1 CADDTechnician General 3 CADDTechnician General 4 EITCoordinator Civil Engineer Civil Engineer Civil Sr Environmental EIT EIT Electrical Engineer Electrical Engineer Electrical Sr EIT Mechanical Engineer Mechanical Engineer Mechanical Sr Engineer Soils Engineer Soils Sr EIT Structural Engineer Structural Engineer Structural Sr EIT Water Resources Engineer Water Resources Engineer Water Resources Sr Human Resources Specialist Sr Management Consultant Sr SectionManager/Teaml-eader National Technical Director ATTACHMENT "B" CONTRACT 1516011 $60.00 - $200.00 - $50.00 - $50.00 - $50.00 - $90.00 - $110.00 - $120.00 - $120.00 - $50.00 - $80.00 - $120.00 - $80.00 - $100.00 - $140.00 - $80.00 $80.00 - $120.00 - $130.00 - $100.00 - $90.00 - $160.00 $120.00 - $140.00 - $80.00 - $120.00 $150.00 $30.00 - $80.00 - $160.00 - $120.00 - $160.00 - $110.00 - $260.00 - Note: All rates are subject to adjustment on January 1 of each year. $70.00 $230.00 $60.00 $90.00 $110.00 $100.00 $120.00 $140.00 $140.00 $60.00 $150.00 $170.00 $120.00 $160.00 $260.00 $90.00 $120.00 $190.00 $250.00 $120.00 $160.00 $270.00 $140.00 $210.00 $100.00 $150.00 $240.00 $120.00 $100.00 $180.00 $140.00 $270.00 $260.00 $290.00 ATTACHMENT "B" CONTRACT 1516011 HDR HYDROPOWER STANDARD HOURLY RATE SHEET FOR 2015 (in US Dollars) Associate Managing Principal $220.00 - $310.00 Bus Unit Mgr/Managing Prin $230.00 - $270.00 Marketing Coordinator Sr $70.00 - $120.00 Marketing Services Manager $150.00 - $170.00 Project Controller $70.00 - $120.00 Project Manager Engineer Asst $110.00 - $130.00 Project Manager Engineer $180.00 - $260.00 Project Manager Engineer Sr $170.00 - $240.00 Project Manager General $120.00 - $230.00 Project Manager General Sr $200.00 - $260.00 Environmental Planner 1 $70.00 - $90.00 Environmental Planner 2 $80.00 - $110.00 Environmental Planner 3 $140.00 - $190.00 Program Manager $230.00 - $260.00 Technical Editor $90.00 - $110.00 Biologist 1 $60.00 - $80.00 Biologist 2 $80.00 - $100.00 Biologist 3 $100.00 - $210.00 CulturalResourceSpecialist 1 $80.00 - $100.00 CulturalResourceSpecialist 2 $110.00 - $120.00. CulturalResourceSpecialist 3 $100.00 - $130.00 Environmental Scientist 1 $70.00 - $90.00 Environmental Scientist 2 $80.00 - $160.00 Environmental Scientist 3 $90.00 - $200.00 GIS Analyst $80.00 - $110.00 Senior GIS Analyst $90.00 - $140.00 Geologist 2 $70.00 - $110.00 Geologist 3 $180.00 - $200.00 Hydrologist 2 $100.00 - $180.00 Technician General 2 $80.00 - $100.00 Technician General 4 $140.00 - $160.00 Note: All rates are subject to adjustment on January 1 of each year.