HomeMy WebLinkAboutKeough's Landscaping 2014-06-16 i . . I
CONTRACT 1314239 I�
, Orchard Substation Landscape Maintenance
This Agreement is made and entered on June 16, 2014, in Okiah, California,
I by and between Keough' s Landscaping, a corporation ("Contractor") and the City
of Ukiah ( "City") , a general law municipal corporation.
RECITALS:
l . The plans and specifications for this work ( "the Work") are contained '
in Exhibit A, which is attached hereto and incorporated herein by this reference.
' 2 . Contractor is properly licensed and qualified to perform the work.
3 . Whenever this Agreement calls for City approval or notification, the I
' approval or notification must be signed by its Electric Otility Director or his
or her designee .
IAGREEMENT:
Wherefore, in consideration of the foregoing facts and the terms and
conditions as further stated herein, the parties hereby agree as follows .
1. PERFORMANCE OF THE WORR ;
I Contractor wi11 perform the Work as further provided herein.
1 .1 Time o£ Performance. Contractor sha11 commence performance of services I
as required by the Scoperof-WOrk upon receipt of the Notice to Proceed and shall li
complete such services within 3 years from the date of this agreement. Contractor
shall complete the work to the City' s reasonable satisfaction, even if contract
disputes arise or Contractor contends it is entitled to further compensation.
1. 1 . 1 . ❑ ��ne�x �F aPPi��abie� It is agreed by the parties to the contract
that time is of the essence and that, in case all the work is not completed
before or upon the expiration of the time limit as set forth, damage, other �i
than those cost items identified in section 1 . 1 . 2, will be sustained by the !
City and that it is and will be impracticable to determine the actual amount
of damage by reason of such delay; and it is therefore agreed that, subject
to Sections 1 . 13-1 . 19 , below, the Contractor will pay to the City the sum of
five hundred dollars (5500 . 00) per day for each and every calendar day' s delay
Ibeyond the time prescribed. �I
S:u\agr[ms06\s�oct fo�m cons.rieilon contzaet I
June lti, 3014
1
�
I _ �
�
I1 . 1 . 2 ❑ [�ne�k �t aPPi,��nie� In case the work called for under this contract
is not completed within the time limit stipulated herein, the City shall have
the right as provided hereinabove, to extend the time of completion thereof.
If the time limit be so extended, the City shall have the right to charge to
the Contractor and to deduct from the final payment for the work the actual '
cost to the City of engineering, inspection, superintendence and other overhead �
expenses which are directly chargeable to the contract and which accrue during
the period of such extension, except that the cost of final unavoidable delays
shall not be included in such charges .
1.2 Construction of Contract Documents. Contractor will perform the Work
in compliance with the plans and specifications set forth in the attached Exhibit
A. If there is any inconsistency or conflict between the plans and the
specifications, the specifications will prevail . If there is any inconsistency �
between the plans and the specifications and this agreement, the terms of this
Agreement shall prevail, unless expressly stated otherwise in a particular
specification.
1 .3 Contractor £urnished items . Contractor will furnish all necessary
labor, materials, tools, equipment, and transportation necessary to perform the
Work.
1 . 4 Use of Employees .
1 . 4 . 1 . Contractor shall pay a11 mechanics and laborers employed
or working upon the site of the work unconditionally and without subsequent
deductions or rebate on any account the full amounts due at the time of payment
at wage rates not less than those contained in the applicable prevailing wage
determination, regardless of any contractual relationship which may be alleged
to exist between the Contractor and subcontractors and such laborers and
mechanics . '
1 . 4 .2 . Contractor shall comply with the California Labor Code
Section 1775 . In accordance with said Section 1775, Contractor shall forfeit as
a penalty to the City, 550 . 00 for each calendar day or portion thereof, for each
workman paid less than the stipulated prevailing rates for such work or craft
in which such workman is employed for any work done under the Contract by him
or her or by any subcontractor under him or her in violation of the provisions
of the Labor Code and in particular, Labor Code Sections 1770 to 1780, inclusive.
In addition to said penalty and pursuant to Section 1775, the difference between i
such stipulated prevailing wage rates and the amount paid to each workman for
each calendar day or portion thereof for which each workman was paid less than
the stipulated prevailing wage rate shall be paid to each workman by the
� S:uVa3='-'rs�6Astmri -.,rm _o.i.,.r..ct_on ronr_ra:: ��
June 18, '�:i4
2
�
. ' i
Contractor.
1 . 4 . 3 . Pursuant to the provision of Section 1770 of the Labor Code
of the State of California, City has ascertained the general prevailing rate of
wages (which rate includes employer payments for health and welfare, vacation,
pension and similar purposes) applicable to the work to be done, for straight �
time work. The holiday wage rate listed shall be applicable to all holidays
recognized in the collective bargaining agreement of the particular craft,
classification, or type of workers concerned. Copies of the General Prevailing
Wage Determination are on file in the office of the City Engineer and are available
to the Contractor on request . The Contractor shall post the wage determination
at the site of work in a prominent place where the workers can easily see it. i
I
1 . 4 . 9 . City will not recognize any claim for additional
compensation because the Contractor has paid any rate in excess of the prevailing
wage rate obtained from the City Engineer. The possibility of wage increases is
one of the elements to be considered by the Contractor in determining his or her
bid and will not in any circumstances be considered as the basis for a claim
against the City.
1 . 4 . 5 . Travel and Subsistence Payments .
Contractor shall make travel and subsistence payments to each worker
needed to execute the work i� accordance with the requirements in Section 1773. 8
of the Labor Code (Chapter 880, Statutes of 1968) . i
1 . 4 . 6. Apprentices .
Attention is directed to the provisions in Sections 1777 . 5 (Chapter
14ll, Statutes of 1968) and 1777 . 6 of the California Labor Code concerning the
employment of apprentices by the Contractor or any subcontractor under him.
Contractor and any subcontractor under him or her shall comply with the
requirements of said sections in the employment of apprentices .
Information relative to apprenticeship standards, wage schedules and
other requirements may be obtained from the Director of Industrial Relations,
ex officio the Administrator of Apprenticeship, San Francisco, California, or '
from the Division of Apprenticeship Standards and its branch offices .
Copies of Labor Code Sections 1771 (requirinq prevailing wages) , 1775 (imposing
penalties, including a $50 per day, per worker forfeiture, for failure to pay
prevailing wages) , 1776 (requiring contractor to maintain available for
inspection certified payroll records) , 1777 . 5 (requiring certain apprenticeship
programs) , 1813 (imposing penalties for failure to make records available for
,��, �s�,ti��.���rr eof �o�.��«�-<i�a ��a�:d��. �
June 15, '0_�
3
I
inspection) and 1815 (requiring time and � for overtime) are attached to this
Contract as Exhibit B.
1.5 CITY Inspector. CITY may designate an architect, engineer, other design
professional or other inspector ( "Inspector") to supervise and/or inspect j
Contractor ' s performance of the Work. The Inspector shall have no authority to �
change the Work, the compensation for performing the Work or the time for
completing the Work without City' s prior written approval . City shall notify the �
Contractor in writinq, if it designates an Inspector.
1 . 6 Site Conditions . Contractor acknowledges that it has inspected the work I
site and any improvements involving the Work and satisfied itself as to the I
conditions which can affect the Work or its cost. Contractor has not relied on
any representation by CITY or its officers or employees as to the condition of !
the site or the houses or any condition that might affect the cost of performinq
this Aqreement .
1 . 7 New Products Required. All equipment, materials or fixtures furnished
by Contractor under this Agreement shall be new and of the most suitable grade
for the intended purpose, unless otherwise specifically provided.
1. 8 Compliance with Laws . The Contractor shall give all notices and comply
with all applicable laws, ordinances, codes, rules and regulations . The ;
Contractor shall secure and pay for all permits, fees, and licenses necessary I
for the proper execution and completion of the work. ',
1 . 9 Protection of Site and Improvements . The Contractor shall preserve I
anclprotect the site, grounds and any involved improvements and shall not alter '
or damage any portion thereof, except as is absolutely necessary in order to �i
perform the Work. The Contractor shall repair or replace, as directed by CITY,
any property that it damages, loses or destroys in violation of this paragraph.
Contractor shall assume full responsibility for maintaining the safety of the
worksite in compliance with all applicable state and federal worker safety and
protection laws and shall maintain the worksite in compliance with all such laws.
1 . 10 Inspection of Work. The Contractor shall ensure that the Work is �
available for inspection by CITY or its Inspector at all reasonable times and
that no work is covered up or rendered incapable of inspection without prior
notice to CITY or its Inspector and a reasonable opportunity for inspection. The
presence or absence of an CITY inspector or the conduct of an inspection by CITY
or its Inspector shall not relieve the Contractor from any contract requirement
or compliance with Exhibit A.
� ,.�_.�,�,�.� r:�� r,.«� „�_�,,.«� � ��„� �
��„e �e, :��v. ,
9 I
I �
__ _ _ _ _ _
' 1 .11 Title. The Contractor warrants that it conveys full and complete title,
free of all liens and encumbrances, to all materials, supplies, fixtures and
equipment furnished to CITY under this Agreement and agrees to fully defend and
indemnify CITY, its officers and employees, and the houses and homebuyers
included in the Work from and against any claim, lien, charge, debt, cost, expense i
or liability arising from a breach of said warranty.
I 1. 12 Warranties . In addition to any other warranties in this contract,
the Contractor warrants that the Work conforms to the contract requirements and
is free of any defect in equipment, material or workmanship for a period of one
year from the date of final acceptance of the Work by CITY. If CITY accepts any
Ipart of the Work before final acceptance of the entire Work, the warranty shall
continue for the period of one year from the date of such partial acceptance.
The Contractor shall remedy, at the Contractor ' s expense, anyfailure to conform,
or any defect . [Initial if following sentence applies / / / /] CITY shall retain
s of the Contract Amount to secure the Contractor ' s warranty and shall remit
the unused portion of that amount at the end of the warranty period. The time
limit of this warranty shall not apply to a�y latent defects, or gross negl igence �
or fraud on the part of the Contractor.
1. 13 . Extension of Time.
Should any delays occur which the C.iYy may cons.ider unavoidable, as herein defined, !
the Contractor shall, pursuant to his or her application, be allowed an extensio�
of time proportional to said delay or delays, beyond the time herein set forth,
in which to complete this contract; and liquidated damages for delay sha11 not
be charged against the Contractor by the City during an extension of time granted
because of unavoidable delay or delays.
Any claim by Contractor for a time extension based on unavoidable delays shall
be based on written notice delivered to the City within 15 days of the occurrence
of the event giving rise to the claim. Failure to file said written notice within
the time specified shall constitute a waiver of said claim. Notice of the full
extent of the claim and all supporting data must be delivered to the City within
95 days of the occurrence unless the City specifies in writing a longer period.
All claims for a time extension must be approved by the City and incorporated
into a written change order .
1 . 14. Unfavorable Weather and Other Conditions .
During unfavorable weather and other conditions, the Contractor shall pursue only �
such portions of the work as sha11 not be damaged thereby. No portions of the
work whose satisfactory quality or efficiency will be affected by any unfavorable
i conditions shall be constructed while these conditions remain, unless, by special
means or precautions approved by the City, the Contractor shall be able to
Iovercome them. !
I
::uAaqrrmsn��Ashort fori. �,i. i.r�iar .....i ..� .i
June 1N, Lilln
5
II
—_
_ __ .. _. __.
.
. .
�
The Contractor shall be granted a time extension of one day for each unfavorable
weather day that prevents him or her from placing concrete forms or placing and
, finishing concrete or asphalt concrete. Such unfavorable weather day is defined
as a rain day where precipitation prevents the contractor from performing the
work more than four (4) continuous hours within the authorized work period or
a temperature day where the ambient temperature is below that specified for the I
placement of materials associated with the controlling work item for more than
four (9 ) continuous work hours of the authorized work period.
1.15. Saturday, Sunday, Holiday and Night Work.
No work shall be done between the hours of 6 p.m. and 7 a.m. , nor on Saturdays,
Sundays or legal holidays except such work as is necessary for the proper care
and protection of work already performed, or except in cases of absolute necessity
and in any case only with the permission of the City. I
It is understood, however, that night work may be established as a regular I
procedure by the Contractor if he or she first obtains the written permission I
of the City and that such permission may be revoked at any time by the City if i
the Contractor fails to maintain at night adequate force and equipment for '
reasonable prosecution and to justify inspection of the work.
1. 16. Hours of Labor.
Eight (8) hours of labor shall constitute a legal day' s work and the Contractor
or any subcontractor shall not require or permit more than eight hours of labor
in a day from any person employed by him or her in the performance of the work
under this contract, unless payinq compensation for all hours worked in excess
of eight (8) hours per day at not less than 1 '-� times the basic rate of pay.
The Contractor shall forfeit to the City, as a penalty, the sum of twenty-five
dollars ($25. 00) for each workman employed in the execution of the contract by
him or her or by any subcontractor, for each calendar day during which such laborer,
workman, or mechanic is required or permitted to labor more than eight hours in
violation of the provisions of Section 1810 to 1816, inclusive, (Article 3, I
Chapter l, Part 7, Division 2) of the Labor Code of the State of California and �
any acts amendatory thereof.
2 . CONTRACT PRICE '��
CITY shall pay the Contractor for performance of this Agreement a monthly I
fee of $400 . 00 per month. Additional services provided, not included in the I
original scope of services, will be pre-approved by the City, and will be handled
on a labor and materials basis. Contractor shall be reimbursed those receipted
costs plus fifteen ( 15) percent. Labor costs shall be reimbursed to contractor
at the flat hourly fee of $55. 00 per hour.
�.��A�9rcrosnb�shorr, form �o�struccl�.� � �-���re=t
June tP, .'.ota
6
III
�
_
� �
3 . PAYMENT OF CONTRACT PRZCE
3 . 1 Payment to Cor.tractor for services rendered in accordance with this
contract shall be based upon submission of monthly invoices for the work
satisfactorily performed prior to the date of the invoice less any amount already !
paid to Consultant, which amounts shall be due and payable thirty (30) days after
receipt by City. The invoices shall provide a description of each item of work
performed, the time expended to perform each task, the fees charged for that task, i
and the direct expenses incurred and billed for. Invoices shall be accompanied I
by documentation sufficient to enable City to determine progress made and to �
support the expenses claimed. il
4. INDENIIiIFICATION AND INSURANCE. I�
4 . 1 Indemni£ication. The Contractor shall do all of the work and furnish
all labor, materials, tools and appliances, except as otherwise herein expressly
sti.pulated, necessary or proper for performing and completing the work herein
required in the manner and within the time herein specified. The mention of any
specific duty or liability imposed upon the Contractor shall not be construed
as a limitation or restriction of any general liability or duty imposed upon the 'i
Contractor by this contract, said reference to any specific duty or liability
being made herein merely for the purpose of explanation.
The right of general supervision by the City shall not make the Contractor an
agent of the City and the liability of the Contractor for all damages to persons
or to public or private property, arising from the Contractor' s execution of the
work, shall not be lessened because of such general supervision.
Until the completion and final acceptance by the City of all the work under and
implied by this contract, the work shall be under the Contractor ' s responsible
care and charqe. The Contractor shall rebuild, repair, restore and make qood all
injuries, damages, re-erections and repairs, occasioned or rendered necessary
by causes of any nature whatsoever, excepting only acts of God and none other,
to all or any portions of the work, except as otherwise stipulated.
To the fullest extent permitted by law, Contractor shall indemnify and hold
harmless the City and its officers, directors, agents, and employees from and
against all claims, damages, losses and expenses including but not limited to
attorneys ' fees, costs of suit, expert witness fees and expenses and fees and
costs of any necessary private investigators arising out of or resulting from
the performance of the work, provided that any such claim, damage, loss or expense
(1) is attributable to bodily injury, sickness, disease or death, or to injury
to or destruction of tangible property, other than the work itself, including
the loss of use resulting therefrom and (2) is caused in whole or in part by any
S:Il�39ZLInyOS\ShOZC SOIIR CO:ISCZ�.['L1C11 1O11C:C[t
June id, 2019
7
I
I _. _ — .— _ —._
_�
act or omission of the Contractor, any subcontractor, or anyone directly or
indirectly employed by any of them, or anyone for whose acts any of them may be
liable, regardless of whether or not it is caused in part by a party indemnified
hereunder, or by the negligence or omission of a party indemnified herein.
In any and all claims against the City or any of its agents or employees by any
employee of the Contractor, any subcontractor, anyone directly or indirectly
employed by any of them, or anyone for whose acts any of them may be liable, the
indemnification obliqation shall not be limited in any way by any limitation on
the amount or type of damages, compensation or benefits payable by or for the �
Contractor or any subcontractor under workers ' or workmen ' s compensation acts,
disability benefit acts, or other employee benefit acts. The obligation to
indemnify shall extend to and include acts of the indemnified party which may
be negligent or omissions which may cause negligence .
' The City shall have the right to estimate the amount of such damage and to cause
the City to pay the same and the amount so paid for such damage shall be deducted
from the money due the Contractor under this contract; or the whole or so much
of the money due or to become due the Contractor under this contract as may be i
considered necessary by the City, shall be retained by the City until such suits
or claims for damages shall have been settled or otherwise disposed of and �
satisfactory evidence to that effect furnished to the City.
4.2 Insurance. Contractor shall procure and maintain for the duration of
the contract insurance against claims for injuries to persons or damages to '
property which may arise from or in connection with the performance of the work
hereunder by the Contractor, his or her agents, representatives, employees or
subcontractors .
4.2 . 1. Minimum Scope o£ Insurance
Coverage shail be at least as broad as :
1 . Insurance Services Office Commercial Liability Coverage
(occurrence form CG 0001) .
2 . Insurance Services Office form number CA 0001 (Ed. 1/87 ) covering
Automobile Liability, code 1 (any auto) .
3 . Worker ' s Compensation insurance as required by the State of
California and F.mployer' s Liability Insurance.
4.2 .2 . Minimum Lim.its o£ Insurance
,:.�\�1�'L;^�OG�S}'.C![ f9lT. CO:.SC_lICC1pf`. C�^.:1�:L.'C I�
i ]une 18, 20:5
I B
I _ - .
Contractor shall maintain limits no less than:
1 . General Liability: $1, 000, 000 per occurrence for bodily injury,
personal injury, and property damage. If Commercial General Liability
Insurance or other form with a general aggregate limit is used, either
the general aggregate limit shall apply separately to this
project/location or the general aggregate limit shall be twice the
required occurrence limit.
2 . Automobile Liability: 51, 000, 000 per accident for bodily
injury and property damage.
3 . Employer' s Liability: $1, 000, 000 per accident for bodily
injury and property damage.
4 .2 .3. Deductibles and Self-insured Retentions
Any deductibles or self-insured retentions must be declared to and
approved by the City. At the option of the City, either: the insurer
shall reduce or eliminate such deductibles or self-insured retentions
as respects the City, its officers, officials, employees and
volunteers; or the Contractor shall provide a financial guarantee
satisfactory to the City guaranteeinq payment of losses and related
investigations, claim administration and defense expenses .
4.2 .4. Other Insurance Provisions
The general liability and automobile liability policies are to contain,
or be endorsed to contain, the following provisions :
l . The City, its officers, officials, employees, and volunteers are
to be covered as insureds with respect to liability arising out of
automobiles owned, leased, hired or borrowed by or on behalf of the
contractor; and with respect to liability arising out of work or
, operations performed by or on behalf of the Contractor including
materials, parts or equipment furnished in connection with such work
or operations . General liability coverage can be provided in the form
of an endorsement to the Contractor ' s insurance, or as a separate
owner' s policy.
2 . For any claims related to this project, the Contractor ' s
insurance coverage shall be primary insurance as respects the City, ',
its officers, officials, employees, volunteers . Any insurance or '
self-insurance maintained by the City, its officers, officials,
employees, or volunteers, shall be excess of the Contractor' s
insurance and shall not contribute with it.
S:ll\tl�1IL:��'IE\SYIOYL .�..T �:C(iS�C�C'.lOfl �.[I!1tZdCL
.)uRe lft. 2�15
9 I
,i
I
i —
3 . Each insurance policy required by this clause shall be endorsed
to state that coverage shall not be canceled by either party, except
after thirty (30) days ' prior written notice by certified mail, return
receipt requested, has been given to the City.
4.2 .5. Acceptability of Insurers
Insurance is to be placed with admitted California insurers with an
A.M. Best ' s rating of no less than A- for financial strength, aa for
long-term credit rating and AMB-1 for short-term credi.t rating.
4 .2 . 6. Veri£ication of Coverage
Contractor. sha11 furnish the City with original certificates and
amendatory endorsements effecting coverage required by this clause .
The endorsements shall be on forms provided by the City or on other
than the City' s forms, provided those endorsements or policies conform
to the requirements . A11 certificates and endorsements are to be !
received within 15 days from written notice of contract award, and the II
work shall not commence until the certificates and endorsements have
been approved by the City. The City reserves the right to require
complete certified copies of all required insurance policies,
including endorsements effecting the coverage required by these
Special Provisions at any time.
4 .2 .7. Subcontractors
Contractor shall include all subcontractors as insureds under its
policies or sha11 furnish separate certificates and endorsements for
each subcontractor. All coverages for subcontractors shall be subject
to all of the requirements stated herein.
5 . TERMINATION.
This Agreement may only be terminated by City: 1 ) for breach oY the agreement;
2) because funds are no longer available to pay Contractor for services provided
under this Agreement; or 3) City has abandoned and does not wish to complete the
project for which Contractor was retained. City shall notify Contractor of any '
alleged breach of the agreement and of the action required to cure the breach.
If Contractor fails to cure the breach within the time specified in the notice,
the contract shall be terminated as of that time. If terminated for lack of funds �
or abandonment of the project, the contract shall terminate on the date notice '
of termination is given to Contractor. City shall pay the Contractor only for
services performed and expenses incurred as of the effective termination date,
unless terminated because the Contractor has failed to satisfactorily cure a
S:uAo9nnc;0oAs-�on. fr.�m ..-o�sr_i�c[�ou c�n-_�.. ��
Sone 18. .'.019
IQ
I
. . _. _ _. . . _ . —�
breach after notice in which event City shall:
a. retain any amounts earned under the Contract but not yet paid by City; ;
b. take possession of all material and fixtures on the job site;
c. have the riqht to complete the Work and recover from Contractor any
increased cost to complete the Work above the amounts that would have been paid ,
to Contractor hereunder, toqether with any other damages suffered by City as a �
result of said breach.
6. MODIFICATION OF AGREEMENT. j
City may, from time to time, request changes in the Work, the time to complete
the work or the compensation to be paid for the Work. Such changes must be i
incorporated in written amendments to this Agreement. To be effective, all such
chanqes as referred to in this section must be agreed upon in writing by both
parties to this agreement .
7 . ASSIGNMENT. �I
The Conr.ractor shall not assign any interest in this Agreement, and shall
not transfer any interest in the same (whether by assignment or novation) , without
the prior written consent of City.
8 . APPLICATION OF LAWS.
The parties hereby agree that a11 applicable Federal, State and local rules,
requlations and guidelines not written into this Agreement shall hereby prevail
dur'inq the period of this Agreement.
9. INDEPENDENT CONTRACTOR.
It is the express intention of the parties hereto that Contractor is an
independent contractor and not an employee, joint venturer, or partner of City
for any purpose whatsoever. City shall have no right to, and shall not control
the manner or prescribe the method of accomplishing those services contracted
to and performed by Contractor under this Agreement, and the general public and
all governmental agencies regulating such activity sha11 be so informed.
Those provisions of this Agreement that reserve ultimate authority in City
have been inserted solely to achieve compliance with federal and state laws, rules,
requlations, and interpretations thereof. No such provisions and no other provi-
I
...u\a��rivuU6Ashori (o:m conscrr.cr.ion �.ontracc
0une 1N, 2014
11
I
I . - _ " _ _ .._ _ — �
sions of this Agreement shall be interpreted or construed as creating or
establishing the relationship of employer and employee between Contractor and
City. il
Contractor shall pay all estimated and actual federal and state income and
self-employment taxes that are due the state and federal government and shall
furnish and pay worker' s compensation insurance, unemployment insurance and any
other benefits required by law for himself and his employees, if any. Contrac-
tor agrees to indemnify and hold City and its officers, aqents and employees
harmless from and against any claims or demands by federal, state or local
government agencies for any such taxes or benefits due but not paid by Contractor,
including the legal costs associated with defendinq against any audit, claim, i
demand or law suit.
Contractor warrants and represents that it is a properly licensed for the
work performed under this Agreement with a substantial investment in its business j
and that it maintains its own offices and staff which it will use in performinq
under this Agreement . I
10 . GOVERNING LAW. ',
I'his Agreement shall be governed by and construed in accordance with the '
laws of the State of California and any legal action concerning the agreement
must be filed and litigated in the proper court in Mendocino County, each party
consenting to jurisdiction and venue of California state courts in Mendocino
County.
11 . SEVERABILITY.
If any provision of the Agreement is held by a court of competent
juxisdiction to be invalid, void, or unenforceable, the remaining provisions
shall nevertheless continue in full force and effect without being impaired or
invalidated in any way.
12 . INTEGRATION.
This Agreement, including the exhibits attached hereto, contains the entire
agreement among the parties and supersedes a11 prior and contemporaneous oral
and written agreements, understandings, and representations among the parties.
No amendments to this Agreement shall be binding unless executed in writing by
all of the parties .
13 . WAIVER. ��'
s:��Ae�c-��.e 5 _ .,,_ � �.__,. . -.�_e.._
Sune 18, '_Ois
12
.
I
�
No waiver of any of the provisions of this Agreement shall be deemed, or
shall constitute a waiver of any other provision, nor shall any waiver constitute
a continuing waiver. No waiver shall be binding unless executed in writing by
the party making the waiver. I
14 . NOTICES. I
Whenever notice, payment or other communication is required or permitted
under this Agreement, it shall be deemed to have been given when personally
de_ivered, telefaxed or deposited in the Onited States mail with proper first
class postage affixed thereto and addressed as follows :
CONTRACTOR CITY 'i
Keouqh' s Landscaping, Inc. Cicy of Ukiah
Darrin R. Mcklem Electric Otility Director
525 Boonville Road 300 Seminary Ave.
Ukiah, CA. 95982 Ukiah, CA. 95982 !
FAX: 707-468-8048 FAX: 707-463-6204
Service by telefax shall bear a notation of the date and place of transmission
and the facsimile telephone number to which transmitted.
Either party may change the address to which notices must be sent by providing
notice of that chanqe as provided in this paragraph.
15. PARAGRAPH HEADINGS. �
The paragraph headings contained herein are for convenience and reference
on] y and are not intended to define or limit the scope of this agreement .
16 . DUPLICATE ORIGINALS. �
This Aqreement may be executed in one or more duplicate originals bearinq
the original signature of both parties and when so executed any such duplicate
original shall be admissible as proof of the existence and terms of the Agreement
between the parties.
WHEREFORE, the parties have entered this Agreement on the date first written i
above. j
Keouqh' s Landscaping, Inc. CITY
S:u\aqrcros06\short form coosccucticn roncracc
June 1B, 2014
13
I
_
� �� � �
BY� �c�' ,���/�� By: / ,
�
I Title: ��S^ ' �.�% � Tit Cit Mana er I
� �
Y 9
i
California Contractor ' s License Number: 628798
�
�
I
I
,i
S:uAaqctms06A�hort :orn ronsccovc�on contra.-r
Jnne _B, �U:4
19 I
;
I _